建筑工程施工合同竣工日期的变更条件是怎样的-法律综合法律援助-法律咨询免费平台-国际律师联盟

网站首页词典首页

问题	建筑工程施工合同竣工日期的变更条件是怎样的
释义	法律分析：在建设工程施工过程中，工期的延误有很多原因。从实践来看，工期顺延的理由主要是下列情形： 1、工程量增加； 2、发包人变更设计； 3、发包人未按合同约定的期限提供设计图纸等施工必需的资料； 4、发包人未按约支付工程款； 5、发包人指定的分包人与承包人在施工过程中衔接不当； 6、工程质量鉴定。法律依据：根据最高人民法院《关于审理建设工程施工合同纠纷案件适用法律问题的解释》第15条规定：建设工程竣工前，当事人对工程质量发生争议，工程质量经鉴定合格的，鉴定期间为顺延工期期间。
随便看	补偿性合同的概念是什么补偿方法一般是什么呢公司合同补偿措施有哪些补偿方法一般是什么呢拆迁资产补偿中几种重要的补偿方式补偿方式有哪几种类型 -法律知识补偿形式一般是什么呢？拆件补偿的两种方式法律问题惩罚性赔偿与补偿性赔偿做为补偿和作为补偿的分别是什么无功补偿的三种方式惩罚性赔偿与补偿性赔偿是什么补偿协议有什么作用民间借款与民间借贷的区别民间贷款怎么还款民间小额贷款是什么？民间借贷的借款方式有哪些？农村信用社贷款与民间借贷区别小额贷款怎么还款 -民间借贷民间借贷如何还钱民间小额贷款是什么？民间借贷如何还钱？民间小额贷款是什么？民间借贷如何还钱贷款与民间借贷的区别 member of a delegation member of a joint venture member of a lawyers' association member of a legislature assembly member of a mediation committee member of an editorial board member of an executive council or a board of directors member of a presidium member of armed forces member of a society, club, etc. Member Of Congress Member of Lands Tribunal Member of Parliament member of partnership member of right member of the adjudicatory committee member of the bar member of the Board of Directors member of the Central Committee member of the Chamber of Deputies member of the Chinese People's Political Consultative Conference member of the consular staff member of the court-martial member of the diplomatic staff member of the House of Representatives

法律咨询免费平台收录17839362条法律咨询问答词条，基本涵盖了全部常用法律问题的释义及解答，是法律学习及实务的有利工具。